RFPQ for General Contractors for Construction of Fire Station 120
Closing Date: 03/08/2017 4:00:00 PM ET
This Request for Pre-Qualification (“RFPQ”), is inviting qualified, bondable, General Contractors (“respondents”) to submit their credentials in order to pre-qualify for tendering on the construction of the new Fire Station 120, located at 125 Eglinton Avenue West, Mississauga ON L5M 0P4.
This will be the only pre-qualification advertisement for general contractors for the required construction services. All respondents that pre-qualify as a result of this RFPQ will be invited to bid under Canadian Construction Documents Committee CCDC 2 – 2008 Stipulated Price Contract with Amendments as written by the City of Mississauga (“the City”).
The scope of work will include providing General Contracting Services for the construction of a new 8,300 square foot facility. The project is currently in construction documentation phase, and Alaimo Architecture Inc. (AAI) is the Prime Consultants for this project.
The facility will include:
Fire Station with two truck vehicle bays, gear room, work shop, kitchen, day room, exercise room, washrooms, captain offices and dormitories and utility rooms.
Post disaster design including generator.
All site work including site servicing and landscaping.
Construction Start Date: Spring 2017 Substantial Completion Date: Fall 2018
Contractor Capacity, Qualification and Experience
To qualify, respondents are to prove their capabilities, demonstrate their qualifications and experience in construction projects of similar scope, size, complexity and value. Respondents must have been in the construction contracting business, operating under the same company name for a minimum of 5 years with resources to complete multiple projects simultaneously with a combined annual value of no less than $3 million dollars of construction work annually for the past five years. Respondents to have proven experience as a general contractor with projects similar in scope and size to the project described in the RFPQ; with at least two (2) examples of completed similar projects (new fire station building/post disaster building). Respondents to demonstrate experience as a general contractor with sub-contractors necessary but not limited to earthworks, site servicing, formwork, structural, mechanical electrical and controls and be in full compliance with all Federal, Provincial and Municipal laws and regulations as they pertain to the City of Mississauga. For more information on the City’s purchasing By-law and policies, go to: www.mississauga.ca
300 City Centre Drive, Ground Floor, Materiel Management, Mississauga ON, L5B 3C1, between the hours of 8:30 a.m. to 4:30 p.m. Person Picking-up documents, Courier must provide Procurement #, complete bidder company name, proper mailing address, fax, phone number, contact name and email address of a person responsible for receipt of addenda and other correspondence related to this procurement or documents WILL NOT be released.
$35.31 Method of Payment: Cash, Amex, Visa, MasterCard, Debit Card or Cheque (payable to: City of Mississauga)
Biddingo.com is an online portal that connects suppliers providing various goods and services to 1000+ buyers from the Provincial, Municipal, Education, Crown Corporation,
Construction, Housing and Healthcare sectors, and private companies from across Canada.